Hareychuk, et al v. Sunup Estates, et al, SC-14-6583, unreported Hareychuk v. Sunup, SC-14-6583-00

Issue, cause of action

In the Hareychuk case, allegations contending that construction delays were brought against a pool contractor as well as a landscape contractor.

Factual Summary

Two contracts were entered into by homeowners.  The contracts were vague on when a project would start as well as finish.  Many material specifications, such as choice of style and colour of walkway stone were outstanding.  The project was severely delayed by discovery of a buried electrical line that required relocation.  The project also required municipal approvals.

Apparently frustrated by delays, the homeowner uttered various obscenities, among other things.  The relationship came to an end.  The homeowners hired others to complete the work.

At Trial, the primary Plaintiff failed to appear or testify leaving the Trial judge to take an adverse inference that the testimony of the primary Plaintiff would favour the Defendants.  Additionally, only the Defendant testified as to what was proper workmanship and reasonable.

The Law, application

The Plaintiff's Claim was dismissed and a Defendant's Claim was granted.


86 Kersey Crescent
Courtice, Ontario,
L1E 0A4

P: (800) 551-5751
E: awesome@marketing.legal

Hours of Business:

10:00AM – 8:00PM
10:00AM – 8:00PM
10:00AM – 8:00PM
10:00AM – 8:00PM
10:00AM – 8:00PM

By appointment only.  Please call for details.


Law Clerks
Process Servers
and more.


We Offer a 
FREE ½ Hour Consultation

Marketing.Legal is a 100% Canadian brand, owned and operated incorporated business, with dedicated expert professionals, having decades of qualified experience in Website Development, Search Engine Optimization (SEO), Google Adwords, and Social Media marketing for Lawyers and Paralegals.


SSL Secured
Trust https://marketing.legal

Animated Spinner